Create a free account and describe your company. With the trial, CanPursue checks every opportunity against it and explains the fit.
Create free accountCreate a free account to see past contracts like this one: who won and at what price.
Create free accountTrade Agreement: Agreement on Internal Trade (AIT) Tendering Procedures: All interested suppliers may submit a bid Competitive Procurement Strategy: Comprehensive Land Claim Agreement: No Nature of Requirements:
Wasauksing Swing Bridge Repairs
EQ754-161675/A Dhillon, Ambreen Telephone No. - (416) 590-8253 Fax No. - (416) 512-5862
Public Works and Government ServicesCanada (PWGSC) is issuing an Invitation to Tender (ITT) for a requirement for the timber repairs for the Wasauksing Swing Bridge. All as indicated in the Contract Documents and/or Sections.
The Wasauksing Swing Bridge provides access for vehicles crossing the South Channel of Parry Sound between Seguin Township and Parry Island. The bridge is an operating movable bridge that permits the passage of navigation traffic through the South Channel. The movable span is an equal arm through truss pivot bridge with an overall length of 52.8 m. The spans from the east and west abutments to the swing span nose piers consist of a series of timber trestle spans. The 58.6 m long west approach consists of seventeen (17) spans of both timber pile and post/sill construction and the 42.3 m long east approach consists of twelve (12) spans of similar construction.
Work under this Contract includes repairs to the approach timber tres tle spans. Repairs generally include installation and subsequent removal of temporary supports; supply and installation of pile jackets at 32 locations; construction of reinforced concrete collar mud sills at fourteen (14) piles on the west embankment; placement of concrete mud sills at two (2) bents on the east embankment; installation of new timber braces; and shimming between piles, cap beams, and stringers.
Comply with operational constraints, milestones, and completion dates. Work must be monitored and completed to meet the goals at the mile stones and at the completion date.
Bidders should provide, with their bid or promptly thereafter, a complete list of names of all individualswho are currently directors of the Bidder. If such a list has not been received by the time the evaluation of bids is completed, Canada will inform the Bidder of a time frame within which to provide the information. Failure to provide such a list within the required time frame will render the bid non-responsive. Bidders must always submit the list of directors before contract award.
Canada may, at anytime, request that a Bidder provide properly completed and Signed Consent Forms (Consentto a Criminal Record Verification form - PWGSC-TPSGC 229) for any or all individuals named in the aforementioned list within a specified delay. Failure to provide such Consent Forms within the delay will result in thebid being declared non-responsive.
A COMPLETE LIST OF EACH INDIVIDUAL WHO IS CURRENTLY ON THE BIDDER'S BOARD OF DIRECTORS. (SEE APPENDIX 2 OF THE "ITT" DOCUMENT)
Drawings and Specifications are now available for viewing and downloading in a Portable Document Format (PDF) or in a standard paper version. Tenderers should note that Attachment 1 (ATT 1) contains the Drawings and Specifications Package (DSP) which consists of PDF files organized in an industry recognized directory structure.
Standard Terms and Conditions for this procurement are incorporated by reference into, and form part of the Tender and Contract Documents. The standard Public Works and Government Services Canada documents may be viewed at https://buyandsell.gc.ca/policy-and-guidelines/standard-acquisiti on-clauses-and-conditions-manual
All enquiries of a technical and contractual nature, are to be submitted to the Contracting Officers, AmbreenDhillon e-mail: ambreen.dhillon@pwgsc.gc.ca Telephone: (416) 590-8253, or Facsimile: (416) 512-5862
Bid Receiving: Sealed tenders will be received at Public Works and Government Services Canada, 4900 Yonge Street, Bid Receiving, 12th Floor, Toronto, Ontario M2N 6A6.
The Crown retains the rightto negotiate with suppliers on any procurement.
Documents may be submitted in either official language of Canada.
Delivery Date: 12/11/2015
The Crown retains the right to negotiate with suppliers on any procurement.
Documents may be submitted in either official language of Canada.
Not stated in the notice: procurement type, procurement method, selection criteria, region of delivery, region of opportunity, expected contract period, end user
No attachments listed in the open data.
No contact listed in the open data.